terms of service
These Terms of Service govern your use of the Lux Builds website operated by Harlan Logan Investments LLC dba Lux Builds. By accessing or using this website, you agree to these terms. If you do not agree, please do not use the site.
Note: These terms apply to your use of this website. All active project work is governed by a separate written contract executed between you and Lux Builds. In the event of a conflict, the executed project contract takes precedence.
Last updated: March 2026
This website is provided for informational purposes and to allow prospective clients to submit project inquiries. You agree to use this site only for lawful purposes and in a way that does not infringe on the rights of others.
You may not use this site to transmit unlawful or fraudulent content, attempt unauthorized access to any part of the site or its systems, or use automated tools to scrape or copy content without our written permission.
You may not use this site to transmit unlawful or fraudulent content, attempt unauthorized access to any part of the site or its systems, or use automated tools to scrape or copy content without our written permission.
Use of This Website
Submitting an inquiry through our contact form does not constitute a contract, commitment, or guarantee of services. All inquiries are reviewed at our discretion and do not obligate Lux Builds to respond, take on your project, or provide a quote. Any information you submit will be handled in accordance with our Privacy Policy.
Inquiry Submissions
Project availability, pricing, and timelines referenced on this website are for general informational purposes only and are subject to change. Nothing on this website constitutes a binding estimate, proposal, or commitment. All formal project agreements are governed by a separate written contract.
No Guarantee of Availability or Pricing
Once a project moves forward, the following terms apply and are incorporated into the written project contract:
- Scope of Work: Contractor will furnish all labor, materials, equipment, and supervision necessary to complete the agreed scope. Work not specifically described in the contract is considered excluded and may require a written change order.
- Change Orders: Any changes to the agreed scope of work must be documented in a written change order signed by both parties before work proceeds. Change orders will describe the scope of the change, any adjustment to the contract price, and any impact to the schedule.
- Payment: Payments are due according to the schedule set forth in the project contract. Balances not received within 15 days of the due date may result in suspension of work. Past due balances may accrue interest at 1.5% per month.
- Concealed Conditions: If unforeseen conditions are discovered during construction including structural issues, rot, mold, hazardous materials, or improper prior work, the contract price and schedule will be equitably adjusted by written agreement.
- Owner Responsibilities: Owner is responsible for making all material and finish selections by deadlines established by Contractor. Failure to do so may delay the project and result in additional costs. Owner is also responsible for ensuring safe site access and removing personal property from work areas. Contractor is not responsible for damage to personal property left within construction areas.
- Delays: Construction schedules are estimates. Contractor is not responsible for delays caused by weather, permit delays, material shortages, inspection delays, labor shortages, unforeseen site conditions, or owner-requested changes.
- Subcontractors: Contractor may engage qualified subcontractors to perform portions of the work and remains responsible for their coordination and supervision.
- Warranty: Contractor warrants that all work will be performed in a workmanlike manner consistent with industry standards for a period of two years from substantial completion. This warranty excludes normal wear and tear, owner-supplied materials, and damage caused by others.
- Substantial Completion: Substantial completion occurs when the project is sufficiently complete for its intended use. At that point, both parties will prepare a punch list of remaining minor items. Final payment becomes due upon substantial completion.
- Termination: Contractor may terminate the project agreement upon written notice if Owner materially breaches the agreement, including failure to make payments or interference with the work. Owner shall pay for all work completed, materials ordered, and reasonable termination costs.
- Mechanics Lien Rights: Owner acknowledges that Contractor and subcontractors may have the right to file a mechanics lien against the property for unpaid labor or materials under Pennsylvania law.
Project Contracts
All content on this website including text, images, graphics, logos, and design is the property of Harlan Logan Investments LLC dba Lux Builds. You may not reproduce, distribute, or use any content from this site without our prior written consent.
All drawings, designs, plans, and specifications prepared by Contractor remain Contractor's intellectual property. Owner receives a limited license to use such documents solely for the project and may not reuse or transfer them without written permission.
Contractor reserves the right to photograph completed projects for portfolio and marketing purposes. Owner's personal information will not be disclosed without consent.
All drawings, designs, plans, and specifications prepared by Contractor remain Contractor's intellectual property. Owner receives a limited license to use such documents solely for the project and may not reuse or transfer them without written permission.
Contractor reserves the right to photograph completed projects for portfolio and marketing purposes. Owner's personal information will not be disclosed without consent.
Intellectual Property
To the fullest extent permitted by law, Lux Builds and its owners, employees, and affiliates shall not be liable for any indirect, incidental, or consequential damages arising from your use of this website or reliance on any information contained within it.
Limitation of Liability
The parties agree to attempt to resolve any disputes through good-faith negotiation before pursuing mediation, arbitration, or legal action. The prevailing party in any legal action arising from a project agreement may recover reasonable attorney's fees and costs to the extent permitted by law.
Dispute Resolution
These terms and all project agreements are governed by the laws of the Commonwealth of Pennsylvania.
Governing law
We may update these Terms of Service from time to time. When we do, we will update the date at the top of this page. Continued use of the website after any changes constitutes acceptance of the updated terms.
